28-U.S.C.-1499
§1499 – Liquidated Damages Withheld From Contractors Under Chapter 37 of Title 40
Pathway
Title 28 > Part IV > Chapter 91 > Section 1499
Details
- Reference: Section 1499
- Legend: §1499 – Liquidated Damages Withheld From Contractors Under Chapter 37 of Title 40
- USCode Year: 2013
Provision Content
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
(June 25, 1948, ch. 646, 62 Stat. 942; Pub. L. 87–581, title II, §202(a), Aug. 13, 1962, 76 Stat. 360; Pub. L. 97–164, title I, §133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40, 41; Pub. L. 101–650, title III, §325(b)(7), Dec. 1, 1990, 104 Stat. 5121; Pub. L. 102–572, title IX, §902(a)(1), Oct. 29, 1992, 106 Stat. 4516; Pub. L. 107–217, §3(g)(3), Aug. 21, 2002, 116 Stat. 1299; Pub. L. 109–284, §4(2), Sept. 27, 2006, 120 Stat. 1211.)
Historical and Revision Notes
Based on section 324 of title 40, U.S.C., 1940 ed., Public Buildings, Property and Works (June 19, 1912, ch. 174, §1, 37 Stat. 137).
This section contains only the jurisdictional provision in the last clause of section 324 of title 40, U.S.C., 1940 ed.
Changes in phraseology were made.
Amendments
2006—Pub. L. 109–284 substituted chapter 37 of title 40 for Contract Work Hours and Safety Standards Act in section catchline.
2002—Pub. L. 107–217 substituted section 3703 of title 40 for section 104 of the Contract Work Hours and Safety Standards Act.
1992—Pub. L. 102–572 substituted United States Court of Federal Claims for United States Claims Court.
1990—Pub. L. 101–650 substituted Hours and Safety Standards for Hours Standards in text.
1982—Pub. L. 97–164 substituted Contract Work Hours and Safety Standards Act for Contract Work Hours Standards Act in section catchline and United States Claims Court for Court of Claims in text.
1962—Pub. L. 87–581 amended section generally, substituting Liquidated damages withheld from contractors under Contract Work Hours Standards Act for Penalties imposed against contractors under eight hour law in section catchline, and liquidated damages withheld from a contractor or subcontractor under section 104 of the Contract Work Hours Standards Act for a penalty withheld from a contractor or subcontractor under section 324 of Title 40 in text.
Effective Date of 1992 Amendment
Amendment by Pub. L. 102–572 effective Oct. 29, 1992, see section 911 of Pub. L. 102–572, set out as a note under section 171 of this title.
Effective Date of 1982 Amendment
Amendment by Pub. L. 97–164 effective Oct. 1, 1982, see section 402 of Pub. L. 97–164, set out as a note under section 171 of this title.
Effective Date of 1962 Amendment
Amendment by Pub. L. 87–581 effective 60 days after Aug. 13, 1962, but shall not affect contracts existing or thereafter entered into pursuant to invitations for bids outstanding on Aug. 13, 1962, see section 204 of Pub. L. 87–581, Aug. 13, 1962, 76 Stat. 360.
Continued Jurisdiction Upon Claims Under Section 324 of Former Title 40
Pub. L. 87–581, title II, §202(b), Aug. 13, 1962, 76 Stat. 360, provided that the Court of Claims (now United States Court of Federal Claims) was to continue to have jurisdiction to render judgment upon certain claims for a penalty withheld from a contractor or subcontractor under section 324 of former Title 40, Public Buildings, Property, and Works, in connection with any contract subject to that section existing on the date sixty days after Aug. 13, 1962, or thereafter entered into pursuant to invitations for bids that were outstanding on Aug. 13, 1962.
U.S. Encyclopedia of Law Coverage
28-U.S.C.-1455 in the Legal Encyclopedia: Judiciary
In this entry about 28-U.S.C.-1455, find legal reference material, bibliographies and premiere content related to judiciary in the American Encyclopedia of Law, presenting a comprehensive view of the United States judiciary-specific issues, written by authorities in the field.
28-U.S.C.-1452 in the Legal Encyclopedia: Jurisdiction
In this entry about 28-U.S.C.-1452, find legal reference material, bibliographies and premiere content related to jurisdiction in the American Encyclopedia of Law, presenting a comprehensive view of the United States jurisdiction-specific issues, written by authorities in the field.
Leave a Reply